PART 2022—APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS

Chapter 20—Nuclear Regulatory Commission › Subchapter D—Socioeconomic Programs

Subpart 2022.1—Basic Labor Policies

2022.101-1 General.

The Head of the Contracting Activity shall designate programs or requirements for which it is necessary that contractors be required to notify the Government of actual or potential labor disputes that are delaying or threaten to delay the timely contract performance. Contractor notification shall be made in accordance with FAR 52.222-1, “Notice to the Government of Labor Disputes.”

2022.103-4 Approvals.

The agency approving official for contractor overtime is the contracting officer.

Subpart 2022.9—Nondiscrimination Because of Age

2022.901-70 Contract provisions.

The contracting officer shall insert the provision found at 2052.222-70, Nondiscrimination Because of Age, in all solicitations.